THE STATE OF TEXAS I
COUNTY OF KERB j BE IT REMEMBERED that there was begun and holden on the 8th day
of March 1976 at 10:00 o'clock A. bi,, in the City of Kerrville, Texas, a regular term of the
Commissioners' Court, with the following officers present:
Julius R. Neunhoffer	County Judge			
W. C. Schwethelm	Commissioner	Precinct	No.	1
Clinton bi. Sallee	Commissioner	Precinct	No.	2
Adolph Bartel	Commissioner	Precinct	No.	3
Roger Stone	Commissioner	Precinct	No.	4
and the Court having duly opened, the following proceedings were had:
NO, 12615 ACCEPTANCE OF BID OF TOM BENSON COMPANY, INC,, FOR TWO 1976 FOUR DOOR SEDANS FOR
USE BY KERR COUNTY SHERIFF'S DEPARTMENT
On this the 8th day of March 1976, came on to he considered by the Court the sealed bids for
two 1976 four door sedans for use by the Kerr County Sheriff's Department, as per specifica-
tions on file in the office of the County Clerk. Upon opening and reading the bids filed
with the County Clerk of the Court, it is found that the bid of Tom Benson Company, Inc.,
be accepted as the lowest and best bid, as follows:
Total price for two 1976 model four door Chevrolet sedans ------ $12538.40
Less trade-in of two 1974 model four door Ford sedans ------ $ 5620.60
rlet bid for two units $ 6917.80
Motion made by Commissioner Stone, seconded by Commissioner Sallee and unanimously approved
by the Court.
o-o-o-o-o-o-o-o-o-o
NO, 12616 RESOLUTION AUTHORIZING EXECUTION OF CONTRACT FOR THE CONSTRUCTION OF AN ANNEX TO
THE KERR COUNTY, TEXAS, COURTHOUSE AND JAIL BUlI,DING
THE STATE OF TEXAS ~
COUNTY OF KERR
ON THIS, the 8th day of March, 1976, the Commissioners' Court of Kerr County, Texas,
convened in regular session at the regular meeting place of said Court in the Courthouse at
Kerrville, Texas, the meeting being open to the public and notice of such meeting having
been given in advance as prescribed by Article 6252-17, Section 3A, V.A,T.C.S., caith the
following members of the Court being present and in attendance, to wit:
JULiUS R. NEUNHOFFER COUNTY JUDGE, Presiding, and
W. C. SCHWETHELM ) COMMISSIONER, Precinct No. 1
CLINTON M. SALLEE } COMMISSIONER, Precinct No. 2
ADOLPH BARTEL ) COMMISSIONER, Precinct No, 3
ROGER STONE ) COMMISSIONER, Precinct No. 4
and	with	the	following absent:	NON. constituting a quorum;	and among other proceedings
had	were	the	following:		
The Presiding Officer submitted to the Court the following resolution and order:
WHEREAS, Kerr County, Texas, has heretofore advertised for bids on a certain contract
proposed to be let for the construction of an Annex to the Kerr County, Texas, Courthouse
and Jail Building; and
WHEREAS, bids for the aforementioned contract were received, opened, read aloud and
referred to the County's Architect and Engineer for such project for checking and tabulation;
and
WHEREAS, said Architect and Engineer have reported to this governing body that the ~,
lowest and best bid received for said contract was the bid submitted by Waco Construction,
Incorporated, Piaco, Texas, in the amount of $856,900, and has recommended that such bid be

accepted and this governing body enter into and execute the following contract with said
ti~aco Construction, Incorporated, to wit:
THE ADIERICAN INSTITUTE OF ARCHITECTS
AIA Document A101
Standard Form of Agreement Between
owner and Contractor
where the basis of payment is a
STIPULATED SUM
THIS DOCUMENT HAS Ib1P0RTANT LEGAL CONSEQUENCES; CONSULTATION WITH
AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION
Use only with the latest Edition of AIA Document A201, General Conditions of the Contract
for Construction.
This document has been approved and endorsed by The Associated General Contractors of
1
America.
AGREEMENT
made this Eighth (8th) day of Fiarch in the year of Nineteen Hundred and Seventy Six
BETWEEN the Owner: KERB COUNTY, TEXAS
and the Contractor: WACO CONSTRUCTION, INC., P. O. Hox 3216, 6011 Bosque Blvd., Waco,
Texas, 76707
the Project: Kerrville/Kerr County Correction/Detention Facility and Annex to Xerr County
Courthouse
the Architect: A. B. Swank FAIA & Lester B. Whitton PE, Architect & Engineer
The Owner and the Contractor agree as set forth below.
ARTICLE 1
THE CONTRACT DOCUMENTS
The Contract Documents consist of this Agreement, Conditions of the Contract (General,
Supplementary and other Conditions), Drawings, Specifications, all Addenda issued prior to
execution of this Agreement and all Modifications issued subsequent thereto. These form the
Contract, and all are as fully a part of the Contract as if attached to this Agreement or
repeated herein. An enumeration of the Contract Documents appears in Article 7.
ARTICLE 2
THE WORK
The Contractor shall pezform all the bvork required by the Contract Documents for
(Here insert the caption descriptive of the Work as used on other Contract Documents)
Kerrville/Kerr County Correction/Detention I~'aci].ity and Annex to Kerr County Courthouse
ARTICLE 3
TIME OF COMMENCEMENT AND COMPLETION
2
The Work to be performed under this Contract shall be commenced within ten (10) days from
the date of this Agreement and completed within three hundred sixty five (365) calendar days
(consecutive)
(Here insert any special provisions for liquidated damages relating to failure to complete
on time.)
For each calendar day the Work remains uncompleted beyond this date, or the increased time
granted by the Owner, the sum of Two Hundred Do7].ars ($200.00) per day will be deducted from
the monies due the Contractor as liquidated damages.
ARTICLE 4
CONTRACT SUM
_- --- - -- - - - _ __._._ _._ _ _. _. _ = -- - - _ I ~ ~ _ .
The Owner shall pay the Contractor for the performance of the tilork, subject to additions and
deductions by Chance order as provided in the Conditions of the Contract, in current funds,
the Contract Sum of Eight Hundred Fifty Six Thousand Nine Hundred Dollars ($856,900)
(State here the lump sum amount, unit prices, or both, as desired.)
ARTICLE 5
PROGRESS PAYMENTS
Based upon Applications for Payment submitted to the Architect by the Contractor and Certifi-
cates for Payment issued by the Architect, the Owner shall make progress payments on account
of the Contract Sum to the Contractor as provided in the Conditions of the Contract as follows:
On or about the seventh (7th) day of each month ninety (90) per cent of the proportion of
the Contract Sum properly allocable to labor, materials and equipment incorporated in the
64ork and ninety (90) per cent of the portion of the Contract Sum properly allocable to
materials and equipment suitably stored at the site or at some other location agreed upon
in writing by the partias, up to three (3) days prior to the date on which the Application
for Payment is submitted, less the agclregate of previous payments in each case.
(If not covered elsewhere in the Contract Documents, here insert any provision for limiting ._.
or reducing the amount retained after the Y7ork reaches a certain stage of completion.)
until completion of fifty percent (500) of the work at which time the entire amount of the
approved application for payment will be certified for payment provided, (1) that the execu-
tion of the Project is being accomplished in a manner satisfactory to the Owner and Architect,
and (2) that the Owner receives written approval of this procedure from the Company furnishing
the required Performance and Labor and b:aterial Payment Bonds; and upon Substantial Completion
of the entire work, a sum sufficient to increase payments to ninety five percent (95) of the
Contract Sum, less such retain ages as the Architect shall determine £or all incomplete work
and unsettled claims.
Any moneys not paid when due to either party under this Contract shall bear interest at the
legal rate in force at the place of the Project.
ARTICLE 6
FINAL PAYMENT
Final payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by
the Owner to the Contractor thirty (30) days after Substantial Completion of the t;ork unless
otherwise stipulated in the Certificate of Substantial Completion, provided the Work has been
completed, the Contract fully performed, and a final Certificate for Payment has been issued
by the Architect.
ARTICLE 7
bIISCELLANEOUS PROVISIONS
used
7.1 Terr,~s/in this Agreement which are defined in the Conditions of the Contract shall have
the meanings designated in those Conditions.
7.2 The Contract Documents, which constitute the entire agreement between the Owner and
the Contractor, are listed in Article 1 and, except for Modifications issued after execution
of this Agreement, are enumerated as follows:
(List below the Agreement, Conditions of the Contract (General, Supplementary, and other
Conditions), Drawings, Specifications, Addenda and accepted Alternates, showing page or sheet
numbers in all cases and dates where applicable.)
Drawings: All with issue date of 15 January 1976, prepared by A. B. Swank FAIR
3
and Lester B. i•7hitton PE, Architect & Ennineer, consisting of:
Architectural: Sheets 1 thru 20 inclusive
Structural: Sheets S-1 thru 5-11 inclusive
Mechanical: Sheets ME-1, bi-2 thru M-8 inclusive
Electrical: Sheets Me-1, E-2 thru E-6 inclusive
Specifications: All dated 15 January 1976, prepared by A. B. Swank FA L4 & Lester
B. tdhitton PE, Architect & Engineer, including the General Conditions
of the Contract £or Construction, AIA Document A201 April 1970 Edition,
and Addendum No. 1 dated 23 February 1976 consisting of pages 1 thru 3
inclusive with accompanying Sheets 1 and 2 of Drawing SH S8 R (dated
20 February)
4
(SEAL - WACO CONSTRUCTION INC)
ATTEST /s/ Billie R. Brownfield
Title: Secretary
This Agreement executed the day and year first written above.
KERR COUNTY, TEXAS
06dNER by: /s/ Julius R. Neunhoffer CONTRACTOR
Title: County Judge
ATTEST jsj Emmie M. Muenker
County Clerk, Kerr County
(SEAL )
WACO CONSTRUCTION, INC,
by: /sj Robert L. Hoover, Jr
ROBERT L. HOOVER, JR
Title: Exec, V. P.
TFiE AMERICAN INSTITUTE OF ARCHITECTS
AIA Document A311
Performance Bond
KNOid ALL MEN BY THESE PRESENTS: that
(Here insert full name and address or legal title of
Contractor)
WACO CONSTRUCTION, INC.
P. O. Box 3216
Waco, Texas 76707
as Principal, hereinafter called Contractor, and,
SELECT INSURANCE COMPANYnsert full name and address or legal Surety)f
Dallas, Texas 75219
as Surety, hereinafter called Surety, are held and firmly bound unto
(Here insert full name and address or legal title of
Owner)
KERR COUNTY, TEXAS
Kerrville, Texas
as Obligee, hereinafter called Owner, in the amount of
--- Eight hundred fifty six thousand nine hundred and nof100 -----
Dollars ($856,900.00),
for the pal~rnent whereof Contractor and Surety bind themselves, their heirs, executors,
administrators, successors and assigns, jointly and severally, firmly by these presents.
SdHEREAS, ~1AC0 CONSTRUCTION, INC.
Contractor has by written agreement dated March 8th 1976, entered into a contract ~vith Owner
for
(Here insert full name, address and description of project)
Construction of Ierrville/Kerr County Correction/Detention racility and Annex to Kerr County
Courthouse
in accordance with Drawings and Specifications prepared by
( Isere insert full name and address or legal
title of Architect)
A. B. Swank & Lester B. Whitton, P. E,
4310-F Westside, Dallas, Texas
which contract is by reference made a part hereof, and is hereinafter referred to as the
Contract.
1
PERFORMANCE BOND
NOW, THT,'REFORE, THE CONDITION OF THIS OBLIGP.TION is such that, if Contractor shall promptly
and faithfully perform said Contract, then this obligation shall be null and void; otherwise
it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or extension of time made by the Owner.
Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the
Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the
default, or shall promptly
1) Complete the Contract in accordance with its terms and conditions, or
2) Obtain a bid or bids for completin, the Contract in accordance with its terms and
conditions, and upon determination by Surety of the lowest responsible bidder, or, if the
Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible
bidder, arrange for a contract between such bidder and Owner, and make available as work
progresses (even though there should be a default or a succession of defaults under the
contract or contracts of completion arranged under this paragraph) sufficient funds to pay
the cost o£ completion less the balance of the contract price; but not exceeding, including
other costs and damages for which the Surety may be liable hereunder, the amount set forth
in the first paragraph hereof. The term "balance of the contract price," as used in this
paragraph, shall mean the total amount payable by Owner to Contractor under the Contract
and any amendments thereto, less the amount properly paid by Owner to Contractor.
Any suit under this bond must be instituted before the expiration of two (2) years from the
date on which final payment under the Contract falls due.
No right of action shall accrue on this bond to or for the use of any person or corporation
other than the Owner named herein or the heirs, executors, administrators or successors of
the Owner.
Signed and sealed this 8th day of March 1976.
WACO CONSTRUCTION, INC.
(Principal) (Seal)
/s/ Shirley Tennison
(Witness) By /s/ Robert L. Hoover, Jr.
ROBERT L. HOOVER, JR,
(Title)
Exec V.P.
SELECT INSURANCE COMPANY
(Surety) (Seal)
/s/ G Easley
(witness) By /s/ Willard Crotty
ELL IS GROTTY POWERS & CO. (Title)
1000 FIDELITY UNION TOWER /t/ Willard Crotty, Attorney-in-Fact
DALLAS, TEXAS 75201
Tel. (214) 744 4311
THE AMERICAN INSTITUTE OF ARCHITECTS
AIA Document A311
Labor and Material Payment Bond
THIS BOND IS ISSUED 57MULTANEOUSLY
WITH PERFORMANCE BOND IN FAVOK OF
THE OWNER CONDITIONED ON THE FULL
AND FAITHFUL PERFORMANCE Or^ THE
CONTRACT
KNOTd ALL MEN BY THESE PRESENTS: that
(Here insert full name and address or legal title of
Contractor)
4iAC0 CONSTRUCTION, INC.
P. O. Box 3216
Waco, Texas 76707
as Principal, hereinafter called Principal, and
(Here insert full name and address or legal title o£ Surety)
SELECT INSURANCE COMPANY
Dallas, Texas 75219

2
as Surety, hereinafter called Surety, are held and firmly bound unto
iHere insert full name and address or legal title of Owner)
KERt COUL7TY, TEXAS
Kerrville, Texas
as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow
3
defined, in the amount of -- Einht hundred fifty six thousand nine hundred and noj100 ---
(Here insert a sum equal to at least one-half of the contract price) Dollars
($856,900.00 for the payment whereof Frincinal and Surety bind themselves, their heirs,
executors, administrators, successors and assigns, jointly and severally, firmly by these
presents.
WHEREAS, WACO CGNSTRUCTION, INC.
Frincinal has by written agreement dated March Eth 1976, entered into a contract with Owner
for (fIere insert full name, address and description of project)
Construction of Kerrville/Kerr County CorrectionjDetention °acility and Annex to Kerr County
Courthouse
in accordance with Drawings and Specifications prepared by
(Here insert full name and address or legal title of Architect)
A. B. Sorank Y Lester B. Whitton, F. E.
4310-F westside, Dallas, Texas
which contract is by reference made a Hart hereof, and is hereinafter referred to as the
Contract.
LABOR AND Mt1TERIAL PAI'I~iENT BOi1D
NO,'i, THEREr^ORE, THE CONDITION Or THIS OBLIGATION is such that, if Principal shall promptly
make payment to all claimants as hereinafter defined, for all labor and material used or
reasonably required for use in the performance of the Contract, then this obligation shall
Y>e void; otherwise it shall remain in full force and effect, subject, however, to the follow-
ing conditions:
1. A claimant is defined as one having a direct contract with the Principal or witir a
Subcontractor of the Principal for labor, material, or both, used or reasonably required for
use in the performance of the Contract, labor and material bein, construed to include that
part of water, gas, power, light, heat, oil, gasoline, telephone service or rental of equip-
went directly applicable to the Contract.
2. The above named Principal and Surety hereby jointly and severally agree with the O:aner
that every claimant as herein defined, who has not been paid in £ull before the expiration
of a period of ninety (90) days after the date on which the last of such claimant's work or
labor was done or performed, or materials were furnished by such claimant, may sue on this
bond for the use of such claimant, prosecute the suit to final judgment for such sum or sums
as :nay be justly due claimant, and have execution thereon. The Owner shall not he liable
for the payment of any costs or expenses of any such suit.
3. No suit or action shall be commenced hereunder by any claimant:
a) Unless claimant, other than one having a direct contract caith the Principal, shall have
niven written notice to any t~eo of the following: the Principal, the Otaner, or the Surety
above named, within ninety (90) days after such claimant did or performed the last of the
caork or labor, or furnished the last of the materials for which. said claim is made, stating
with substantial accuracy the amount claimed and the name of the party to whom the materials
were furnished, or for whom the work or labor was done or performed. Such notice shall be
served by mailing the same by re,istered mail or certified mail, postage prepaid, in an
envelope addressed to the Principal, Ot-rner or Surety, at any place where an office is

regularly maintained for the transaction of business, or served in any manner in which
le7al process may be served in the state in which the aforesaid project is located, save that
such service need not be made by a public officer.
b) After the expiration of one (1) year following the date on which Principal ceased Work
on said Contract, it being understood, however, that if any limitation embodied in this bond
is prohibited by any law controlling the construction hereof such limitation shall be deemed
to be amended so as to be eau al to the minimum period of limitation permitted by such law.
c) Other than in a state court of competent jurisdiction in and for the county or other
political subdivision of the state in cahich the Project, or any part thereof, is situated,
or in the United States District Court for the district in which the Project, or any part
thereof, is situated, and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of any payment or payments
made in good faith hereunder, inclusive of the payment by Surety of mechanics' liens which
may be filed of record against said improvement, whether or not claim for the amount of such
lien be presented under and against this bond.
Signed and sealed this 8th day o£ A".arch 1976.
CtiACO CONSTRUCTION, INC.
(Principal) (Seal)
/s/ Shirley Tennison gy /s/ Robert L, Hoover, Jr.
(Witness) ROBERT L. HOOVER, JR.
Erec V, P. (Title)
SELECT INSURANCE' COMPANY
(Surety) (Seal)
/s/ G Easley
(Witness) By /s/ C~7illard Crotty
(Title)
/t/ `.~illard Crotty, Attorney-in-Fact
ELLIS GROTTY POWERS & CO.
1000 FIDELITY UNTON TOWER
DALLAS, TEXAS 75201
Tel. (214) 744 4311
POCdER OF ATTORNEY
Y:NOW ALL MEN BY THESE PRESENTS:
That SELECT INSURANCE COMPANY, a corporation o£ the State of Texas, hereinafter called
Company, does hereby appoint PORTER ELLIS, WILLARD GROTTY, JAMES N. POWERS, TOM P. ELLIS, III
GLADYS EASLEY, PETER A. RUSH, WILLIAM G. RLINGMAN, CdILLIAM B. STEELF., JR., JOHN E. I2ATLIFF,
WILLIAM D. BIRDSONG, DALLAS, TEXAS its true and lawful Attorney-in-fact to make, execute, seal
and deliver on its behalf, as surety, any and all bonds and undertakings of Suretyshi».
The execution of such bonds or undertakings in pursuance of these presents shall be as bind-
ing upon the Company as if they had been executed and acknowledged by the regularly elected
officers of the Company.
This Power of attorney is issued pursuant to and by authority of the following resolution of
the Board of Directors of the Company, adopted effective September 29, 1961, and now in
full force and effect:
°iZesolved that the President or any Vice lresident or any Secretary may appoint Attorneys-
in-fact in any State, Territory or Federal District to represent this company and to act on
its behalf within the scope of the authority granted to them in writing, which authority ^~ay
include the potaer to make, execute, seal and deliver on behalf of this Company as surety ,
and as its act and deed any and all bonds and undertakings of suretyship and other documents
that the ordinary course of surety business may require, including authority to appoint agents
for the service of process in any jurisdiction, State or Federal and authority to attest to
the signature of the President or any Vice President. or any Secretary and to verify any
4
affidavit or ether statement relating to the foregoing, and to certify to a copy of any of
the by-laws of the Company and to any resolutions adopted by its Board of Directors; and any
such Attorney-in-fact may be .removed and the authority granted him revoked by the President or
any Vice President or any Secretary or ly the Board of Directors."
This Power of Attorney and Certificate of Authority is signed and sealed by facsimile under
and by authority of the following resolution voted by the Board of Directors of the Select
Insurance Co. at a meeting duly called and held on the 24th of July, 1973.
"Resolved that the signatures of Idarren J. Kwedar, President, or of Frederick Boger, Senior
Vice President, or of Arthur C, wierden, Vice President, or of Jack W. Maynard, Vice President,
or of lailliam E. ,Elston, Vice President, or of Douglas Simpson, Secretary, or of ~. C.
Fetherston, Secretary, and the seal of the Company may be affixed by facsimile to any power
of attorney or to any certificate relating thereto appointing i'~ttorneys-in-fact for purposes
only of executing and attesting bonds and undertakings and other writings obli;atory in the
nature thereof, and any such power of attorney or certificate bearin, such facsimile signature
or facsimile seal shall be valid and binding upon the Company and any such power so executed
and certified by such facsimile sinnature and tacsimile seal shall be valid and binding upon
the Company in the future with respect to any bond or undertaking to which it is attached."
In witness whereof, the Company has caused this Power of Attorney to he signed and its cor-
porate seal to be affixed by its authorized officer this 14th day of January 1976.
By /s/ J 4l Maynard
/t/ Jack W. Maynard Vice President
{Seal)
STATE OF TEXAS Y
ss:
COUNTY OF DALLAS I
On this 14th day of January 1976, before me, a Notary Public of the State and County afore-
said, residing therein, duly commissioned and sworn, personally came the above named officer
of the Company, who being by me first duly sworn according to law, did depose and say that
he is that officer of the Company described in and which executed the foregoing instrument;
that he knocas the seal of the Company; that the seal affixed to such instrument is the
corporate seal of the Company; and that the corporate seal and his signature as such officer
were affixed and subscribed to the said instrument by the authority and direction of the
Company.
(Seal)
/s/ Clifford R. Beard
/s/ CLIFFORD R. BEAKD NOTARY PUBLIC
My commission expires the 1st day of June 1977
CERTIFICATE
I, the undersigned, do hereby certify that the original Power of Attorney of cahich the fore-
going is a true and correct copy is in full force and effect, and the foregoing resolution is
a true and correct transcript from the records of the Company, and that the above named
officer was on the date of execution of the Foregoing Power of Attorney authorized to execute
this Power of Attorney.
In witness whereof, I have hereunto subscribed by name and affixed the corporate seal of the
Company this 8th day of 4iarch 197G.
/s/ Douglas Simpson
/t/ Doucslas Simpson Secretary
(Seal)
AND 1aHEREAS, it is hereby Found and determined that the proposal submitted by Waco
Construction, Incorporated, '~7aco, Texas, for the aforementioned contract was the lowest and
best bid received for the contract proposed to be let by Kerr County, Texas, that said bid
was submitted in accordance caith the plans and specifications for the work to be performed
and in accordance with the terms and conditions set forth in the notice to bidders and this
Commissioners' Court hereby formally accepts such bid; and
WHEREAS, it is now prover for this ~,overning body to approve the execution of the contract
with said bidder and the performance and payment bonds submitted by the aforesaid contractor;
therefore,
BE IT RESOLVED BY THE CO?~11~SISSIONERS' COURT Or THE KERR COUNTY, TEXAS:
SECTION 1: That all of the findings or recitals contained in the preamble hereof are here-
by adopted as a part of this resolution and as a part of the judgment of this Court and are
now incorporated herein as though set forth at lenrtth as a part of this section.
SECTION 2: That the contract set forth in the preamble hereof by and between F.err County,
Texas, and Waco Construction, Incorporated, '.loco, Texas, in the amount of $856,900, is hereby
in all things ratified, approved, confirmed and ado~~ted, and the County Judge and tkie County
Clerk are hereby authorized and directed to execute the same for and on behalf of Kerr County,
•rexas, and as the act and deed of said County and this Commissioners' Court. In addition, the --
payment and performance bonds submi±ted by loco Construction, Incorporated, 17aco, Texas, each
in the Ball amount of the contract price, are hereby approved and ordered annexed or attached
to the contract hereby authorized to he executed.
SECTION 3: That the contractual obligation hereby incurred by Kerr County, Texas, shall
be paid as follow=s:
1) $760,000 from bond funds available from the sale of Kerr County, Texas, General
Obligation Bonds, Series 1976; any
2) $96,900 from funds realized from the sale of the "Kerr County, Texas, Certificates of
Gbli?ation, Series 1976",
all of such foregoin7 funds being hereby appropriated and set aside to pay the contractual
obligation hereby incurred and shall be used for no other purpose.
~ + ~ * n ~
The above resolution having been read in full, it was moved by Commissioner Stone and ....
seconded by Commissioner Sallee that the same be passed and adopted. Thereupon the question
being called for, the County Judge put the motion to a vote of the members of the Commis-
sioners' Court, and the motion carried by the folloFnnq vote: County Judge Neunhoffer and
Commissioners Schcaethelm, Sallee, Bartel and Stone voted "AYE"; and none voted "NO".
The Count~+ Judge declared the motion carried and the order passed and the Clerk was ~ //~
instructed to record same in the proper minutes of the Court.
PASSED AND APPROVED, this the 8th day of March, 1976.
/s/ Julius R. Neunhoffer
County Judge, Kerr County, Texas
ATTEST:
/s/ Emmie M. Pluenker
County Clerk, Kerr County, Texas
(Seal)
o-o-o-o-o-o-o-o-o-o